Trade Agreement: Agreement on Internal Trade (AIT)
Tendering Procedures: All interested suppliers may submit a bid
Competitive Procurement Strategy:
Comprehensive Land Claim Agreement: No
Nature of Requirements:
Wasauksing Swing Bridge Repairs
EQ754-161675/A
Dhillon, Ambreen
Telephone No. - (416) 590-8253
Fax No. - (416) 512-5862
Public Works and Government ServicesCanada (PWGSC) is issuing
an Invitation to Tender (ITT) for a requirement for the timber repairs
for the Wasauksing Swing Bridge. All as indicated in the Contract
Documents and/or Sections.
The Wasauksing Swing Bridge provides access for vehicles crossing the
South Channel of Parry Sound between Seguin Township and Parry
Island. The bridge is an operating movable bridge that permits the
passage of navigation traffic through the South Channel. The movable
span is an equal arm through truss pivot bridge with an overall length
of 52.8 m. The spans from the east and west abutments to the swing span
nose piers
consist of a series of timber trestle spans. The 58.6 m long west
approach consists of seventeen (17) spans of both timber pile and
post/sill construction and the 42.3 m long east approach consists of
twelve (12) spans of similar construction.
Work under this Contract includes repairs to the approach timber tres
tle spans. Repairs generally include installation and subsequent
removal of temporary supports; supply and installation of pile jackets
at 32 locations; construction of reinforced concrete collar mud sills
at
fourteen (14) piles on the west embankment; placement of concrete mud
sills at two (2) bents on the east embankment; installation of new
timber braces; and shimming between piles, cap beams, and stringers.
Comply with operational constraints, milestones, and completion dates.
Work must be monitored and completed to meet the goals at the mile
stones and at the completion date.
Bidders should provide, with their bid or promptly thereafter, a
complete list of names of all individualswho are currently
directors of the Bidder. If such a list has not been received
by the time the evaluation of bids is completed, Canada will
inform the Bidder of a time frame within which to provide the
information. Failure to provide such a list within the required
time frame will render the bid non-responsive. Bidders must
always submit the list of directors before contract award.
Canada may, at anytime, request that a Bidder provide properly
completed and Signed Consent Forms (Consentto a Criminal Record
Verification form - PWGSC-TPSGC 229) for any or all individuals
named in the aforementioned list within a specified delay.
Failure to provide such Consent Forms within the delay will
result in thebid being declared non-responsive.
A COMPLETE LIST OF EACH INDIVIDUAL WHO IS CURRENTLY ON THE
BIDDER'S BOARD OF DIRECTORS. (SEE APPENDIX 2 OF THE "ITT"
DOCUMENT)
Drawings and Specifications are now available for viewing and
downloading in a Portable Document Format (PDF) or in a standard
paper version. Tenderers should note that Attachment 1 (ATT 1)
contains the Drawings and Specifications Package (DSP) which
consists of PDF files organized in an industry recognized
directory structure.
Standard Terms and Conditions for this procurement are
incorporated by reference into, and form part of the Tender and
Contract Documents. The standard Public Works and Government
Services Canada documents may be viewed at
https://buyandsell.gc.ca/policy-and-guidelines/standa…
on-clauses-and-conditions-manual
All enquiries of a technical and contractual nature, are to be
submitted to the Contracting Officers, AmbreenDhillon e-mail:
a••••••••@•••••.••.ca Telephone: (416) 590-8253, or
Facsimile: (416) 512-5862
Bid Receiving: Sealed tenders will be received at Public Works
and Government Services Canada, 4900 Yonge Street, Bid
Receiving, 12th Floor, Toronto, Ontario M2N 6A6.
The Crown retains the rightto negotiate with suppliers on any
procurement.
Documents may be submitted in either official language of Canada.
Delivery Date: 12/11/2015
The Crown retains the right to negotiate with suppliers on any procurement.
Documents may be submitted in either official language of Canada.
