Trade Agreement: Canadian Free Trade Agreement (CFTA)
Tendering Procedures: All interested suppliers may submit a bid
Competitive Procurement Strategy: Best Overall Proposal
Comprehensive Land Claim Agreement: No
Nature of Requirements:
CCIW Transformer Recapitalization Burlington, ON
KW405-220207/B
Kwan, Isaac
Telephone No. - (343) 573-3068 ( )
DESCRIPTION OF PROJECT
Public Works and Government Services Canada (PWGSC), Real Property Branch requires a qualified general contractor to carry out CCIW TRANSFORMER RECAPILIZATION AND RELATED WORKS at Burlington, Ontario
This work shall be in accordance with the Specifications for Project No. KW405-180719/001/PWL CCIW Transformer Recapitalization and their respective Drawings.
The work includes but is not limited to: general construction and modification to the existing site to allow for replacement of three transformers, located at Canada Centre of Inland Water at Burlington, ON. Including all require services and verifications like phase rotation, orientation etc. to be completed with the existing electrical system in order to successfully replace and operate the new transformers
COMPLETION DATE
The Contractor shall perform and complete the Work within Thirty (30) weeks from the date of notification of acceptance of the offer.
ENQUIRIES
All enquiries of a technical and contractual nature, are to be submitted to the Contracting Officer, Isaac Kwan e-mail address: i••••••••@•••••.••.ca
Any clarifications or changes to the bid solicitation resulting from the site visit will be included as an amendment to the bid solicitation.
Delivery Date: 22/09/2021
The Crown retains the right to negotiate with suppliers on any procurement.
Documents may be submitted in either official language of Canada.
